Home | Terms & conditions

Terms & Conditions

CONDITIONS OF SALE:

  1. Special manufactured goods cannot be accepted back for credit at any stage.
  2. By the accepting the quotation and/or given an order conformation for the purchase products form Elecmec this terms and conditions will be binding.
  3. The order cannot be cancelled, once in process.
  4. Our quotation excludes delivery, crating and/or installation, except otherwise specified.
  5. The Nut Machine Company Pty Ltd and our installation team (Elecmec Engineering & Power cc) cannot be held liable for any mismatches or ineffective working of components, unless commissioning and installation is done by us.
  6. Special manufacturing or new designs is based upon what we understand from our customer.
  7. The quotation includes only the items specified on the quotation and any additional work or material or parts required will only be supplied after an additional written quotation has been approved by the customer and a deposit has been paid.
  8. Installation and/or delivery is only included if specifically stated in the quotation.
  9. If any additional changes have to be made, the costs will be for the customer account.
  10. The customer is responsible for the safekeeping of materials and machinery after it has been delivered unto the customer premises or site.
  11. The customer will also ensure that all material delivered to premises or site will be protected form the elements including rain, fire and theft and any other natural causes, any loss will be for customers account.
  12. When working on customers premises or site we will need workers and/or availability of supervisor with authority  from customer  to assist The Nut Machine Company team.
  13. The Nut Machine Company can not be held accountable for any third-party theft or damage to materials and machinery, it will be on the customers account.
  14. All goods remain the property of The Nut Machine Company until paid in full.
  15. If any dispute, credit or return arise the claim amount may not be more than the amount on the invoice.

TERMS

100% payment with conformation of order or as specified on quotation. 

NB: Work can only commence when deposit is cleared by the bank, and final contractual agreement has been signed. No work will be done on Sundays.

ORDERS

Placing an order with The Nut Machine Company Pty Ltd and/or our installations team (Elecmec Engineering & Power cc) means you agree and accept our terms & conditions.

AVAILABILITY

Normal delivery time +/- 4 – 10 working weeks, ex manufacture, subject to receipt of material, prior sales and receipt of full deposit
OR otherwise specified on quotation.

VALIDITY

5 DAYS from date of quotation or as otherwise indicated.

WARRANTY

After delivery or installation and full payment
    1. Equipment is guaranteed against faulty components, workmanship and design for a period of 12 months after installation is done by a qualified electrician for the warranty to take effect.
    2. If any dispute accrued, a formal notice will be given before any legal actions are taken.
    3. If any claim arise for lost of income or product damage the same dispute will be implemented.
    4. Our guarantee does not cover any consequential loss, damage or injury resulting from failure of our equipment whatsoever.
    5. Any mis-use of equipment will forfeit warranty.
    6. No warranty will be in place if the product/equipment/machine is NOT used for the purpose it was intended for.
    7. Any changes without consent of manufacture will forfeit warranty.
    8. No equipment is guaranteed if foreign particles are processed with the nuts i.e. stones, sticks, bolts, nuts etc. (it remains the customers responsibility to make sure nuts are clean of debris)
    9. “In the event that any dispute, claim, or legal proceeding arises out of or in connection with this transaction, such matter shall be submitted to and adjudicated exclusively by the competent courts of South Africa, and both parties hereby consent to the jurisdiction of such courts for the resolution of any such matters

PLEASE TAKE NOTE OF THE FOLLOWING EXCLUSIONS:

               1. Any damage found to have been caused during transport or moving of machinery.

               2. Any damaged caused through incorrect installation of machinery, electrical supply or air supply.

               3. Any damage caused through negligence or lack of maintenance to equipment or parts.

               4. Any excessive wear and tear of machines parts caused by lack of maintenance.

               5. Any damage caused to equipment through operation by unqualified or unauthorized personal.

               6. Any damage caused through use of equipment for purposes other than its intended use.

DAMAGE LIABILITY

  1. The Nut Machine Company Pty Ltd and our installation team cannot be held liable for any consequential loss whether suffered or incurred by the customer or otherwise and irrespective of whether such loss or damage arises directly or indirectly from the product/equipment/machine provided by The Nut Machine Company Pty Ltd or installation team to the customer.
  2. If, contrary to The Nut Machine Company Pty Ltd and our installation team any liability is deemed to arise, than such liability is limited and shall not in any aggregate to exceed to the payment price.

COMPLETION DATES

  1. The customer must adhere to as specified above or quotation for seamless completion of project.
  2. Only upon receiving the deposit will The Nut Machine Company allocate the necessary resources for the project and if deposits are delayed it will affect the delivery dates as quoted.
  3. It is vital importance that the customer confirms and/or adhere the delivery date giving, as work needs to be allocated into our production schedule.
  4. If any other 3rd party is not done with previous work, we need to be informed about new dates to be on site and payments may not be held back.

QUALITY ASSURANCE

The price quoted is based upon most suppliers Standard Level of Quality Assurance (ISO 9001). The cost adherence to any other or additional requirements shall be for the account of the Customer.

FORCE MAJEURE

No liability should extend to us or our sub-contractors for any delay, impossibility of delivery or default in terms of contract, where such delay is due to fires, tempest, acts of God, malicious acts of third party, lockouts, embargoes, breakdown of machinery, insurrection of riots, or any other cause of similar nature to circumstances beyond our control.